Legals for 8-18-11

Legal NoticeRUTH W. ATTAWAYCLERK OF CIRCUIT COURT20859 CENTRAL AVENUE, EASTBLOUNTSTOWN, FLORIDA 32424NOTICE OF APPLICATIONFOR TAX DEEDNOTICE IS HEREBY GIVEN THAT Denzel Dockery is the holder of the following certificate has filed said certificate for a tax deed to be issued thereon. The certificate number and year of issuance, the description of the property, and the names in which it was assessed are as follows;CERTIFICATE NO.425, YEAR OF ISSUANCE 2004DESCRIPTION OF PROPERTYParcel # R04-1N-11-0070-0000-080ALot 8 A of the Subdivision of Cherokee Acres, situated in Section 4, Township 1 North, Range 11 West, described as follows: COMMENCE at and existing concrete monument marking the Northeast Corner of Section 4, Township 1 North, Range 11 West, Calhoun County, Florida; thence South 00 Degrees 02 Minutes 27 Seconds West along the East boundary of said Section 4, for a distance of 1337.85 feet; thence South 89 Degrees 37 minutes 46 Seconds West for a distance of 2299.69 feet, to an iron rod, said rod being the POINT OF BEGINNING, thence South 00 Degrees 06 Minutes 23 Seconds West for 670.20 feet to an iron rod; thence North 89 Degrees 59 Minutes 54 Seconds West for 323.89 feet, to an iron rod; thence North 00 Degrees 09 Minutes 58 Seconds West for 667.91 feet to an iron rod; thence 89 Degrees 37 Minutes 47 Seconds East for 355.06 feet to the POINT OF BEGINNING. BEING TOGETHER with an easement for ingress and egress, and utility purposes described as being the North 30 feet of the SE 1/4 of NE 1/4 and the North 30 feet, of the SW 1/4 of NE 1/4 and the North 30 feet of the SE 1/4 of NW 1/4 of Section 4, Township 1 North, Range 11 West.Said parcel being located entirely in the SW 1/4 of NE 1/4 of Section 4, Township 1 North, Range 11 West, Calhoun County, Florida, and containing 4.98 acres, more or less. Said parcel is also being subject toan easement for ingress, engress and utility purposes across the North 30 feet and the West 30 feet thereof.NAME IN WHICH ASSESSEDLakehill Farms C/O Shawn Savury44 Richard Hill Rd.Craryville, NY 12521-5125Said property being in the County of CALHOUN, STATE OF FLORIDA. Unless such certificate shall be redeemed according to law, the property described in such certificate shall be SOLD to the highest bidder at the Courthouse door on September 1, 2011 At 10:00 A.M. CST.By; Robie BennettDeputy ClerkRUTH W. ATTAWAYClerk of Circuit Court of Calhoun County, FloridaLegal NoticeBID NOTICESTATE HOUSING INITAITIVES“SHIP PROGRAM” The Calhoun Board of County Commissioners will accept sealed bids on behalf of its State Housing Initiatives Partnership “SHIP” Program for the rehabilitation on houses until 12:00 p.m. local time on Tuesday, September 20, 2011. Bids may be delivered to the Clerk’s Office in the Calhoun County Courthouse, Blountstown, Florida 32424. Bids must arrive before deadline. Bids will be opened at 2:00 p.m. or as soon afterwards as possible. Bids must be sealed in an envelope marked “sealed bid for ship rehab” and identified by the name of the firm, and the date and time of the bid opening.A mandatory pre-bid conference will be held on Thursday, September 1, 2011, at 9:00 a.m. local time in room 117 in the Calhoun County Building Department located on the 1st floor of the Calhoun County Courthouse. Bid sheets and specifications will be available at the meeting. It is the responsibility of the contractor to purchase all permits deemed necessary. Bidders must provide proof of general liability and workman’s compensation insurance in the bid package. The insurance must be in force at the time of the bid opening. As an alternative to providing workman’s compensation insurance, the prospective bidder shall provide proof of worker’s compensation exemption. Any person claiming to be exempt shall be subject to an on-the-job inspection for proof of exemption and license of all workers on job site.Minority contractors are encouraged to participate. Calhoun County is an equal opportunity jurisdiction. The Calhoun County Board of County Commissioners reserves the right to reject any and all bids and to waive any informality. The signing of the contract is contingent upon the approval of and/or release of funds by the Florida housing finance agency.CALHOUN COUNTY IS /AN EQUAL OPPORTUNITY/FAIR HOUSING COUNTY.Legal NoticeRUTH W. ATTAWAYCLERK OF CIRCUIT COURT20859 CENTRAL AVENUE, EASTBLOUNTSTOWN, FLORIDA 32424NOTICE OF APPLICATIONFOR TAX DEEDNOTICE IS HEREBY GIVEN THAT Larry Waldorff is the holder of the following certificate has filed said certificate for a tax deed to be issued thereon. The certificate number and year of issuance, the description of the property, and the names in which it was assessed are as follows;CERTIFICATE NO.44, YEAR OF ISSUANCE 2007DESCRIPTION OF PROPERTYParcel # R29-1N- 08-1300-0000-1300Lot 13 of the replat of Yon and Guilford Addition of Calhoun County, according to the plat therof recorded in the Public Records of Calhoun County, Florida, and being a sub-division of the NE 1/4 of the SW 1/4 and the NW 1/4 of the SW 1/4 of Section 29, Township 1 North, Range 8 West.(1) One 1996 General Cougar Doublewide Mobile Home ID# GMHGA4169611059A and GMHGA4169611059BNAME IN WHICH ASSESSEDBlountstown Health Investors C/O Dominion Management GrpPO Box 1667Hickory, NC 28603 Said property being in the County of CALHOUN, STATE OF FLORIDA. Unless such certificate shall be redeemed according to law, the property described in such certificate shall be SOLD to the highest bidder at the Courthouse door on October 6, 2011 At 10:00 A.M. CST.By; Robie BennettDeputy ClerkRUTH W. ATTAWAYClerk of Circuit Court of Calhoun County, FloridaLegal NoticeIN THE CIRCUIT COURT FORCALHOUN COUNTY, FLORIDAPROBATE DIVISIONIN RE: ESTATE OFSTEPHEN ARKWRIGHT BADHAMCASE NO: 1993-032 PRNOTICEPLEASE TAKE NOTICE that on the 1st day of April, 2004 there was placed on deposit in this office, funds received in the estate of Stephen Arkwright Badham (deceased) in the amount of $942.95. Said funds are all of the assets due to:Unknown heir of (deceased) whose address is unknown and said assets remain unclaimed.Unless said funds are claimed on or before six (6) months from the date of the first publication of this notice, said funds will be forwarded to the State of Florida, pursuant to Florida Statutes 744.534.IN WITNESS WHEREOF I have set my hand and official seal at Blountstown, Calhoun County, Florida, on the 10th day of August, 2011.Ruth W. AttawayClerk of Circuit CourtLegal NoticeIN THE CIRCUIT COURT FORCALHOUN COUNTY, FLORIDAPROBATE DIVISIONIN RE: Guardianship ofEDDIE KEARLEYCASE NO: 2003-005 GINOTICEPLEASE TAKE NOTICE that on the 10th day of January, 2006, and on the 18th day of May, 2006 there was placed on deposit in this office, funds received from Karen P. Campbell, as Guardian of the estate of Eddie Kearley (deceased Ward) in the amount of $30.00 and $15.05. Said funds are all of the assets due to:Unknown heir of (deceased) whose address is unknown and said assets remain unclaimed.Unless said funds are claimed on or before six (6) months from the date of the first publication of this notice, said funds will be forwarded to the State of Florida, pursuant to Florida Statutes 744.534.IN WITNESS WHEREOF I have set my hand and official seal at Blountstown, Calhoun County, Florida, on the 10th day of August, 2011.Ruth W. AttawayClerk of Circuit CourtLegal NoticeIN THE CIRCUIT COURT FORCALHOUN COUNTY, FLORIDAPROBATE DIVISIONIN RE: Guardianship ofMARGOT BRADLEYCASE NO: 2003-006 GINOTICEPLEASE TAKE NOTICE that on the 3rd day of June, 2005, there was placed on deposit in this office, funds received from Karen P. Campbell, as Guardian of the estate of Margot Bradley (deceased Ward) in the amount of $3195.11. Said funds are all of the assets due to:Unknown heir of (deceased) whose address is unknown and said assets remain unclaimed.Unless said funds are claimed on or before six (6) months from the date of the first publication of this notice, said funds will be forwarded to the State of Florida, pursuant to Florida Statutes 744.534.IN WITNESS WHEREOF I have set my hand and official seal at Blountstown, Calhoun County, Florida, on the 10th day of August, 2011.Ruth W. AttawayClerk of Circuit CourtLegal NoticeIN THE CIRCUIT COURT FORCALHOUN COUNTY, FLORIDAPROBATE DIVISIONIN RE: ESTATE OFVICKI MICHELLE WESTCASE NO: 2003-039 PRNOTICEPLEASE TAKE NOTICE that on the 11th day of April, 2005 there was placed on deposit in this office, funds received in the estate of Vicki Michelle West (deceased) in the amount of $10,817.46. Said funds are all of the assets due to:Unknown heir of (deceased) whose address is unknown and said assets remain unclaimed.Unless said funds are claimed on or before six (6) months from the date of the first publication of this notice, said funds will be forwarded to the State of Florida, pursuant to Florida Statutes 744.534.IN WITNESS WHEREOF I have set my hand and official seal at Blountstown, Calhoun County, Florida, on the 10th day of August, 2011.Ruth W. AttawayClerk of Circuit CourtLegal NoticeIN THE CIRCUIT COURT FORCALHOUN COUNTY, FLORIDAPROBATE DIVISIONIN RE: Guardianship ofLUVERN SMITHCASE NO: 2004-003 PRNOTICEPLEASE TAKE NOTICE that on the 3rd day of January, 2008, there was placed on deposit in this office, funds received from Karen P. Campbell, as Guardian of the estate of Luvern Smith (deceased Ward) in the amount of$105.25. Said funds are all of the assets due to:Unknown heir of (deceased) whose address is unknown and said assets remain unclaimed.Unless said funds are claimed on or before six (6) months from the date of the first publication of this notice, said funds will be forwarded to the State of Florida, pursuant to Florida Statutes 744.534.IN WITNESS WHEREOF I have set my hand and official seal at Blountstown, Calhoun County, Florida, on the 10th day of August, 2011.Ruth W. AttawayClerk of Circuit CourtLegal NoticeCALHOUN COUNTY 2010-2011FEMA REPAIRS, GROUP 4NOTICE TO RECEIVE SEALED BIDSThe Calhoun County Board of County Commissioners will receive sealed bids from any qualified person, company or corporation interested in constructing:CALHOUN COUNTY 2010-2011 FEMA REPAIRS, GROUP 4Plans and specifications can be obtained at Preble-Rish, Inc., 20684 Central Avenue East, Blountstown, FL 32424, (850) 674-3300. The bid must conform to Section 287.133(3) Florida Statutes, on public entity crimes.OCHEESSEE LANDING ROAD – DR 1831 PW 672/2-6CHARLES PIPPIN ROAD – DR 1831 PW 670/2-5FRED TYRE ROAD – DR 1831 PW 671/2-9JIM GREEN ROAD – DR 1831 PW 555/2-8This project is a roadway construction project, which consists of grading, shaping, and compacting limerock base, reworking shoulders and ditch cleaning and shaping.All bidders shall be pre-qualified with the Florida Department of Transportation per Section 2-1 of the F.D.O.T. Standard Specifications for Road and Bridge Construction, 2010 edition for: FLEXIBLE PAVINGCompletion date for these projects will be 180 days from the date of the Notice to Proceed presented to the successful bidder. Liquidated damages for failure to complete the project on the specified date will be set at $200.00 per day.Please indicate on the envelope that this is a sealed bid, the bid number and what the bid is for.Bids will be received until 12:00 p.m. (C.T.), on Tuesday, September 6, 2011 , at the Calhoun County Clerk’s Office, Calhoun County Courthouse, 20859 Central Avenue East, Room 130, Blountstown, Florida 32424, and will be opened and read aloud on Tuesday, September 6, 2011 at 2:00 p.m. (C.T.)Cost for Plans and Specifications will be $75.00 per set and is non-refundable. Checks should be made payable to PREBLE-RISH, INC.The Board of County Commissioners reserves the right to waive informalities in any bid, to accept and/or reject any or all bids, and to accept the bid that in their judgment will be in the best interest of Calhoun County. If you have any questions, please call Donald Stanley at (850) 674-3300: stanleyd@preble-rish.com.Legal NoticeCALHOUN COUNTY 2010-2011FEMA REPAIRS, GROUP 3NOTICE TO RECEIVE SEALED BIDSThe Calhoun County Board of County Commissioners will receive sealed bids from any qualified person, company or corporation interested in constructing:CALHOUN COUNTY 2010-2011 FEMA REPAIRS, GROUP 3Plans and specifications can be obtained at Preble-Rish, Inc., 20684 Central Avenue East, Blountstown, FL 32424, (850) 674-3300. The bid must conform to Section 287.133(3) Florida Statutes, on public entity crimes.COUNTY ROAD 12 – DR 1785 PW 1613/5-17COUNTY ROAD 9 – DR 1785 PW 1579/5-18This project is a roadway construction project, which consists of grading, shaping, and compacting limerock base, reworking shoulders and ditch cleaning and shaping.All bidders shall be pre-qualified with the Florida Department of Transportation per Section 2-1 of the F.D.O.T. Standard Specifications for Road and Bridge Construction, 2010 edition for:FLEXIBLE PAVINGCompletion date for these projects will be 180 days from the date of the Notice to Proceed presented to the successful bidder. Liquidated damages for failure to complete the project on the specified date will be set at $200.00 per day.Please indicate on the envelope that this is a sealed bid, the bid number and what the bid is for.Bids will be received until 12:00 p.m. (C.T.), on Tuesday, September 6 , 2011 , at the Calhoun County Clerk’s Office, Calhoun County Courthouse, 20859 Central Avenue East, Room 130, Blountstown, Florida 32424, and will be opened and read aloud on Tuesday, _September_6, 2011 at 2:00 p.m. (C.T.)Cost for Plans and Specifications will be $75.00 per set and is non-refundable. Checks should be made payable to PREBLE-RISH, INC.The Board of County Commissioners reserves the right to waive informalities in any bid, to accept and/or reject any or all bids, and to accept the bid that in their judgment will be in the best interest of Calhoun County. If you have any questions, please call Donald Stanley at (850) 674-3300 or stanleyd@preble-rish.com.Legal NoticeNOTICE OF POTENTIAL VOTERREGISTRATION INELIGIBILITY Notice is hereby given to the following individuals at their last-known address: Angela S. Hall, 18858 NW Bob Guilford Rd, Blountstown FL 32424Crystal G. Landrum, 25387 NE Fuqua Cir, Altha, FL 32421Adarrell L. Edwards, 15958 SE Jeffery St, Blountstown FL 32424You are hereby notified that your eligibility to vote is in question. You are required to contact the Supervisor of Elections in Blountstown, Florida, no later than thirty (30) days after the date of this publishing. Failure to respond will result in a determination of ineligibility by the supervisor and your name will be removed from the statewide voter registration system. Published one time on August 17, 2011, in The County Record, Blountstown, Florida. MARGIE C. LARAMORECALHOUN COUNTY SUPERVISOR OF ELECTIONS20859 CENTRAL AVE. EAST, RM. G-10BLOUNTSTOWN, FL 32424PHONE (850) 674-8568