Legals for 04-28-11

Legal NoticeBID NOTICESTATE HOUSING INITAITIVES“SHIP PROGRAM” The Calhoun Board of County Commissioners will accept sealed bids on behalf of its State Housing Initiatives Partnership “SHIP” Program for the rehabilitation on houses until 12:00 p.m. local time on Tuesday, May 3, 2011. Bids may be delivered to the Clerk’s Office in the Calhoun County Courthouse, Blountstown, Florida 32424. Bids must arrive before deadline. Bids will be opened at 5:00 p.m. or as soon afterwards as possible. Bids must be sealed in an envelope marked “sealed bid for ship rehab” and identified by the name of the firm, and the date and time of the bid opening.A mandatory pre-bid conference will be held on Thursday, April 28, 2011, at 9:00 a.m. local time in room 117 in the Calhoun County Building Department located on the 1st floor of the Calhoun County Courthouse. Bid sheets and specifications will be available at the meeting. It is the responsibility of the contractor to purchase all permits deemed necessary. Bidders must provide proof of general liability and workman’s compensation insurance in the bid package. The insurance must be in force at the time of the bid opening. As an alternative to providing workman’s compensation insurance, the prospective bidder shall provide proof of worker’s compensation exemption. Any person claiming to be exempt shall be subject to an on-the-job inspection for proof of exemption and license of all workers on job site.Minority contractors are encouraged to participate. Calhoun County is an equal opportunity jurisdiction. The Calhoun County Board of County Commissioners reserves the right to reject any and all bids and to waive any informality. The signing of the contract is contingent upon the approval of and/or release of funds by the Florida housing finance agency.CALHOUN COUNTY IS /AN EQUAL OPPORTUNITY/FAIR HOUSING COUNTY.Legal NoticeIN THE CIRCUIT COURT OF THE14th JUDICIAL CIRCUITOF FLORIDA, IN AND FO CALHOUN COUNTYCase #: 2009-CA-000019Deutsche Bank National Trust Company, asTrustee for Morgan Stanley, MSAC 2007-HE5 Plaintiff,-vs-Troy L. McMillian, III and Lisa R. McMillian,Husband, and Wife; Bank of America, NationalAssociation; Defendants.AMENDED NOTICE OF SALE NOTICE IS HEREBY GIVEN pursuant to an Order rescheduling foreclosure sale dated April 8, 2011 entered in Civil Case No. 2009-CA-000019 of the Circuit Court of the 14th Judicial Circuit in and for Calhoun County, Florida, wherein Deutsche Bank National Trust Company, as Trustee for Morgan Stanley, MSAC 2007-HE5, Plaintiff and Troy L. McMillian, III and Lisa R. McMillian, Husband and Wife are defendants, I will sell to the highest and best bidder for cash, ON THE FRONT STEPS OF THE CALHOUN COUNTY COURTHOUSE AT 20859 CENTRAL AVENUE EAST, BLOUNTSTOWN, FLORIDA 32424 AT 11:00 A.M. CENTRAL STANDARD TIME, September 8, 2011, the following described property as set forth in said Final Judgment, to-wit:WEST HALF OF NORTHWEST QUARTER OF SOUTHWEST QUARTER OF NORTHEAST QUARTER, SECTION 32, TOWNSHIP 2 NORTH, RANGE 10 WEST, CALHOUN COUNTY FLORIDA.ALSO:BEGIN AT THE NORTHEAST CORNER OF SOUTHEAST QUARTER OF NORTHWEST QUARTER OF SECTION 32, TOWNSHIP 2 NORTH, RANGE 10 WEST, AND RUN WEST 110 YARDS, THENCE SOUTH 220 YARDS, THENCE EAST 110 YARDS, THENCE NORTH 220 YARDS, TO THE POINT OF BEGINNING. SAID LAND LYING AND BEING IN THE SOUTHEAST QUARTER OF NORTHWEST QUARTER OF SECTION 32, TOWNSHIP 2 NORTH RANGE 10 WEST, SAID LAND BEING BETTER DESCRIBED IN SURVEY DESCRIPTION FROM BOUNDARY SURVEY, AS FOLLOWS:BEGIN AT A 6 INCH SQUARE CONCRETE MONUMENT MARKING THE NORTHEAST CORNER OF THE SOUTHEAST QUARTER OF THE NORTHWEST QUARTER OF SECTION 32, TOWNSHIP 2 NORTH, RANGE 10 WEST, CALHOUN COUNTY, FLORIDA, AND RUN THENCE SOUTH 88 DEGREES 54 MINUTES 26 SECONDS WEST ALONG THE NORTHERLY BOUNDARY OF SAID SOUTHEAST QUARTER OF THE NORTHWEST QUARTER, A DISTANCE OF 316.86 FEET TO THE INTERSECTION OF SAID NORTHERLY BOUNDARY WITH THE SOUTHERLY RIGHT OF WAY BOUNDARY OF COUNTY ROAD NO. 274 (100 FOOT RIGHT OF WAY); THENCE SOUTH 85 DEGREES 48 MINUTES 34 SECONDS WEST ALONG SAID SOUTHERLY RIGHT OF WAY BOUNDARY, A DISTANCE OF 13.17, THENCE SOUTH 00 DEGREES 52 MINUTES 00 SECONDS EAST 659.29 FEET, THENCE NORTH 88 DEGREES 54 MINUTES 26 SECONDS EAST 660.00 FEET, THENCE NORTH 88 DEGREES 54 MINUTES 26 SECONDS EAST 660.00 FEET, THENCE NORTH 00 DEGREES 52 MINUTES 01 SECONDS WEST 660.35 FEET, TO THE NORTHERLY BOUNDARY, OF THE SOUTHWEST QUARTER OF THE NORTHEAST QUARTER OF SAID SECTION 32, THENCE SOUTH 88 DEGREES 47 MINUTES 40 SECONDS WEST ALONG SAID NORTHERLY BOUNDARY A DISTANCE OF 330.00 FEET TO THE POINT OF BEGINNING.ALSO:COMMENCE AT THE NORTHEAST CORNER OF THE SOUTHEAST QUARTER OF THE NORTHWEST QUARTER OF SECTION 32, TOWNSHIP 2 NORTH, RANGE 10 WEST, FOR THE POINT OF BEGINNING, THENCE RUN NORTH 88 DEGREES 47 MINUTES 40 SECONDS EAST, A DISTANCE OF 330.00 FEET, TO THE NORTHEAST CORNER OF LANDS DESCRIBED IN DEED RECORDED IN O.R. BOOK 237, PAGE 625, OF THE PUBLIC RECORDS OF CALHOUN COUNTY, FLORIDA, THENCE RUN NORTH 00 DEGREES 52 MINUTES 01 SECONDS WEST A DISTANCE OF 34.37 FEET, MORE OR LESS, TO THE SOUTH RIGHT OF WAY BOUNDARY OF COUNTY ROAD NO. 274, THENCE RUN IN A SOUTHWESTERLY DIRECTION ALONG THE SOUTH RIGHT OF WAY OF COUNTY ROAD NO. 274, TO THE NORTH BOUNDARY OF LANDS DESCRIBED IN O.R. BOOK 237, PAGE 625, OF THE PUBLIC RECORDS OF CALHOUN COUNTY, FLORIDA, THENCE RUN NORTH 88 DEGREES 54 MINUTES 26 SECONDS EAST, A DISTANCE OF 316.86 FEET, MORE OR LESS, BACK TO THE POINT OF BEGINNING.ANY PERSON CLAIMING AN INTEREST IN THE SURPLUS FROM THE SALE, IF ANY, OTHER THAN THE PROPERTY OWNER AS OF THE DATE OF THE LIS PENDENS MUST FILEA CLAIM WITHIN 60 DAYS AFTER THE SALE. DATED at Blountstown, Florida, this 11th day of April, 2011.Ruth Attaway, Clerk of the Circuit CourtLegal NoticeIN THE FOURTEENTH JUDICIAL CIRCUIT COURT IN AND FORCALHOUN COUNTY, FLORIDAPROBATE DIVISIONFILE NO.:2011-21PRIN RE: ESTATE OF:ROGER H. HENDERSON, Deceased.NOTICE OF CREDITORS(Summary Administration) The administration of the estate of Roger H. Henderson, deceased, whose date of death was February 22, 2011, and whose social security number is xxx-xx-0211, is pending in the Circuit Court for Calhoun County, Florida. Probate Division; the address of which is 20859 East Central Avenue, Blountstown, Florida 32424. The names and addresses of the personal representative and attorney for the personal representative are set forth below. All creditors of the decedent and other persons having claims or demands against decedent’s estate on whom a copy of this notice is required to be served must file their claims with this court WITHIN THREE (3) MONTHS AFTER THE LATER OF THE TIME OF THE FIRST PUBLICATION OF THIS NOTICE ON THEM. All other creditors of the decedent and other persons having claims or demands against decedent’s estate must file their claims with this court WITHIN THREE (3) MONTHS AFTER THE DATE OF THE FIRST PUBLICATION OF THIS NOTICE ALL CLAIMS NOT FILED WITHIN THE TIME PERIODS SET FORTH IN SECTION 733.702 OF THE FLORIDA PROBATE CODE WILL BE FOREVER BARRED. NOTWITHSTANDING THE TIME PERIOD SET FORTH ABOVE, ANY CLAIM FILED TWO (2) OR MORE YEARS AFTER THE DECEDENT’S DATE OF DEATH IS BARRED. THE DATE OF FIRST PUBLICATION OF THIS NOTICE IS April 20, 2011.RICKY LYNN HILLPersonal RepresentativeAttorney for Person Giving NoticeMICHELLE B. TAGERT, ESQ.Florida Bar #0070836FRANK A. BAKER, ESQ.Florida Bar #02097914431 Lafayette StreetMarianna, FL 32446(850) 526-3633Counsel for Personal RepresentativeLegal NoticeIN THE CIRCUIT COURT OF THE FOURTEENTH JUDICIAL CIRCUIT IN AND FORCALHOUN COUNTY,STATE OF FLORIDA. GENERAL CIVIL DIVISIONCASE NUMBER: 2010-CA-000097WELLS FARGO FINANCIAL SYSTEMFLORIDA, INC. Plaintiffs,-vs-DAVID E. RANDALL; JACQUELINE D. RANDALL; andUNKNOWN OCCUPANTS, TENANTS, OWNERS, AND OTHER UNKNOWN PARTIES, including, if a named defendant is deceased, the personal representatives, the surviving spouse, heirs, devisees, grantees, creditors, and all other parties claiming by, through, under or against that defendant, and all claimants, persons or parties, natural or corporate, or whose exact legal status is unknown, claiming under any of the above named or described defendants,  DefendantsNOTICE OF SALE NOTICE is hereby given that pursuant to an Order or Final Judgment entered in this cause, in the Circuit Court of Calhoun County, Florida, I will sell to the property situated in Calhoun County, Florida, described as:EXHIBIT AThe land referred to in this exhibit is located in the County of Calhoun County and the State of Florida in Deed Book 315 at Page 20 and described as follows:Commence at a 6” x 6” concrete monument (St. Joe Paper Company SJPC) marking the northeast corner of Section 1, Township 1 South, Range 10 West, Calhoun County, Florida, thence north 88 degrees 56 minutes 53 seconds west along the north line of said section, a distance of 1,516.59 feet to a 6” x 6” triangle concrete monument (SJPC); marking the intersection of said north line with the west right of way line of State Road No. 73, said monument being on a curve concave northwesterly, having a radius of 2,814.94 feet; thence southwesterly along the arc of said curve; and said right of way line, through a central angle of 22 degrees 10 minutes 40 seconds, a distance of 1089.59 feet (chord of said arc being south 02 degrees 02 minute 08 seconds east, 1082.80 feet); thence leaving said west right of way line, north 69 degrees 39 minutes 11 seconds west along the centerline of a 60 foot ingress, egress and public utilities easement, a distance of 90.27 feet to the beginning of a curve concave southwesterly, having a radius of 200.00 feet; thence northwesterly along the arc of said curve and said centerline, through a central angle of 17 degrees 54 minutes 33 seconds; a distance of 62.51 feet (chord of said arc being north 78 degrees 36 minutes 28 seconds west, 62.26); thence north 87 degrees 33 minutes 44 seconds; west, along said centerline, a distance of 111.79 feet to the beginning of curve concave northeasterly having a radius of 200.00 feet, thence northwesterly along arc of said curve and said centerline, through central angle of 34 degrees 05 minutes 27 seconds, a distance of 119.00 feet (chord of said arc being north 70 degrees 32 minutes 16 seconds west, 117.25 feet); thence north 53 degrees 29 minutes 33 seconds west, along said centerline, a distance of 258.27 feet to the beginning of a curve concave southwesterly having a radius of 400.00 feet; thence northwesterly along the arc of said curve and said right of way line, through a central angle of 40 degrees 48 minutes 10 seconds a distance of 284.86 feet (chord of said arc being north 68 degrees 57 minutes 49 seconds west, 278.88 feet); thence north 89 degrees 21 minutes 54 seconds west, along said centerline, a distance of 351.44 feet to the POINT OF BEGINNING; thence continue north 89 degrees 21 minutes 54 seconds west, along said centerline, a distance of 548.56 feet to the end of said easement; thence south 00 degrees 38 minutes 06 seconds west along the westerly end of said easement, a distance of 30.00 feet; thence south 18 degrees 25 minutes 09 seconds west, a distance of 723.75 feet to a point in the centerline of the Toolchest Branch; thence meander southeasterly and easterly along said centerline, a distance of 581 feet, more or less, to point (aid point being south 84 degrees 44 minutes 59 seconds east, a distance of 564.59 feet from previous point); thence leaving said centerline, north 15 degrees 46 minutes 26 seconds east, a distance of 792.08 feet to the point of beginning. Together with and subject to a 60 foot ingress, egress and public utility easement, 30.00 foot to the left and right of the following described centerline.Commence at a 6” x 6” concrete monument (St. Joe Paper Company – SJPC) marking the northeast corner of section 1, township 1 south, range 10 west, Calhoun County, Florida; thence north 88 degrees 56 minutes 53 seconds west, along the north line of said section, a distance of 1,516.59 feet to a 6” x 6” triangle concrete monument (SJPC) marking the intersection of said north line with the west right of way line of State Road 73, said monument being on a curve concave northwesterly, having a radius of 2,814.94 feet; thence southwesterly along the arc of said curve and said right of way line, through a central angle of 22 degrees 10 minutes 40 seconds, a distance of 1089.59 feet to the point of beginning; thence north 69 degrees 39 minutes 11 seconds west, distance of 90.27 feet to the point of curve of a curve concave southerly, having a radius of 200.00 feet; thence westerly along the arc of said curve through central angle of 17 degrees 54 minutes 33 seconds, a distance of 62.51 feet; thence north 87 degrees 33 minutes 44 seconds west, a distance of 111.79 feet to the point of curve of a curve concave northeasterly, having a radius of 200.00 feet; thence westerly along the arc of said curve, through a central angle of 34 degrees 05 minutes 27 seconds, a distance of 119.00 feet; thence north 53 degrees 29 minutes 33 seconds west, a distance of 258.27 feet, thence north 48 degrees 33 minutes 44 seconds west a distance of 80.88 feet to the point of curve of a curve concave southwesterly, having a radius of 400.00 feet; thence westerly along the arc of said curve through a central angle of 40 degrees 48 minutes 10 seconds, a distance of 284.86 feet; thence north 89 degrees 21 minutes 54 seconds west, a distance of 900.00 feet to the point of terminus.Property address: 11687 SW Ranch Gate Drive, Clarksville, FL 32430Parcel I.D.: 01-1S-10-0000-0001-0204at public sale, to the highest and best bidder, for cash, on the front steps of the Calhoun County Courthouse, 20859 Central Avenue E., Blountstown, Florida 32424 at 11:00 a.m. CST, on May 19, 2011. Any person claiming an interest in the surplus from the sale, if any, other than the property owner as of the date of the Lis Pendens, must file a claim with the Clerk of Court within 60 days after the date.Dated this 12th day of April, 2011.RUTH W. ATTAWAYClerk of the Court, Calhoun CountyLegal NoticeThe Calhoun County School Board proposes to amend policies as required by Florida Statute for the Calhoun County Schools as follows:ADMINISTRATIVE PROCEDURES ACTCALHOUN COUNTY SCHOOLSCHAPTER 5 — STUDENTSAmendPolicy 5.62 Administration of Medication Entire proposals are available for viewing at the School Superintendent’s Office, Room G-20; Calhoun County Court House in Blountstown, Florida. A hearing will be held on the above policies in the Cooperative Extension Building at 20816 Central Avenue East in Blountstown, Florida at the Regular School Board meeting beginning at 5:00 P.M., CDT, Thursday, May 12, 2011Timothy G. Smith, Board ChairCalhoun County School BoardAttest: Wilson T. McClellan, Superintendent Calhoun County SchoolsLegal NoticeNOTICE OF POTENTIAL VOTERREGISTRATION INELIGIBILITY  Notice is hereby given to the following individual at his last-known address: Mack Morgan4607 SW Ethridge/Morgan Ln.,Kinard, FL 32449  You are hereby notified that your eligibility to vote is in question. You are required to contact the Supervisor of Elections in Blountstown, Florida, no later than thirty (30) days after the date of this publishing. Failure to respond will result in a determination of ineligibility by the supervisor and your name will be removed from the statewide voter registration system.Legal NoticeIOLA ROAD HMGP PROJECT PROJECT # 14.187 NOTICE TO RECEIVE SEALED BIDS The Calhoun County Board of County Commissioners will receive sealed bids from any qualified person, company or corporation interested in constructing:IOLA ROAD HMGP PROJECT 1831-05-RIOLA ROAD FEMA REPAIRS DR 1831 PW# 695 Plans and specifications can be obtained at Preble-Rish, Inc., 20684 Central Avenue East, Blountstown, FL 32424, (850) 674-3300. The bid must conform to Section 287.133(3) Florida Statutes, on public entity crimes. This project is a new construction roadway paving project, which consists of grading, shaping, and compacting limerock, reworking shoulders, ditch cleaning and shaping, vegetative treatments, placing asphalt, and striping the roadway. All bidders shall be pre-qualified with the Florida Department of Transportation per Section 2-1 of the F.D.O.T. Standard Specifications for Road and Bridge Construction, 2010 edition, foHot Mix Bituminous Coarse Flexible Pavement Completion date for these projects will be 180 days from the date of the Notice to Proceed presented to the successful bidder.  Liquidated damages for failure to complete the project on the specified date will be set at $200.00 per day. Please indicate on the envelope that this is a sealed bid, the bid number and what the bid is for. Bids will be received until 2:00 p.m. (C.T.), on Tuesday, May 17 , 2011 , at the Calhoun County Clerk’s Office, Calhoun County Courthouse, 20859 Central Avenue East, Room 130, Blountstown, Florida 32424, and will be opened and read aloud on Tuesday, May 17 , 2011, at 5:00 p.m.(C.T.). Cost for Plans and Specifications will be $ 50.00 per set and is non-refundable. Checks should be made payable to PREBLE-RISH, INC. The Board of County Commissioners reserves the right to waive informalities in any bid, to accept and/or reject any or all bids, and to accept the bid that in their judgment will be in the best interest of Calhoun County.  If you have any questions, please contact Matt Carpenter at (850) 674-3300 or mailto:carpenterm@preble-rish.com.Legal NoticeIN THE CIRCUIT COURT, IN AND FOR CALHOUN COUNTYPROBATE DIVISIONCASE NO.:10-31PRIN RE: MARION C. ELDRIDGE, SR Deceased. NOTICE OF CREDITORS The administration of the estate of Marion C. Eldridge, Sr.,deceased whose date of death was July 7, 2010; File Number 10-31-PR is pending in the Circuit Court for Calhoun County, Florida, Probate Division, the address of which is 20859 Central Avenue E, Room 130, Blountstown, Florida 32424. The names and addresses of the Personal Representative and the Personal Representative’s attorney are set forth below. All creditors of the decedent and other persons having claims or demands against decedent’s estate on whom a copy of this notice has been served must file their claims within this court WITHIN THE LATER OF 3 MONTHS AFTER THE DATE OF THE FIRST PUBLICATION OF THIS NOTICE OR 30 DAYS AFTER THE TIME OF SERVICE OF A COPY OF THIS NOTICE ON THEM. All other creditors of the decedent and other persons having claims or demands against decedent’s estate must file their claims with this court WITHIN 3 MONTHS AFTER THE DATE OF THE FIRST PUBLICATION OF THIS NOTICE. ALL CLAIMS NOT SO FILED WILL BE FOREVER BARRED.  NOTWITHSTANDING THE TIME PERIODS SET FORTH ABOVE, ANY CLAIM FILED TWO (2) YEARS OR MORE AFTER THE DECEDENT’S DATE OF DEATH IS BARRED. The date of the first publication of this notice is April 27, 2011.Personal Representative/Curator:Ann L. McCellan16469 SE Main St.Blountstown, Florida 32424Attorney for Personal Representative/Curator:Victoria E. HeulerMcConnaughhay, Duffy, Coonrod,Pope & Weaver, Law Group, P.A.1709 Hermitage Blvd., Suite 200Tallahassee, Florida 32308Telephone: (850)222-8121Fascimile: 840-222-9766