Press "Enter" to skip to content

Legal Notices For 07-30-09

Legal Notices For 07-30-09 Legal Notice INVITATION TO BID Sealed bids will be received by the Calhoun County School Board until 5:00 P.M., CDT, Monday, August 3, 2009, for the purchase of the following: LP Gas for use in lunchrooms and schools of Calhoun County. Any additional information or bid forms required may be obtained at the Office of the School Superintendent, 20859 Central Ave. E., Rm. G-20, Blountstown, Florida. Bid forms must be used by each bidder submitting a bid. Otherwise bids will not be considered. Any bid submitted after the specified hour and date will not be opened or considered. The Board accepts no responsibility for mailed proposals that arrive at the Superintendent’s Office after the above stated time, even though the envelope may reflect a postmark prior to the above date. The Board reserves the right to accept or reject any or all bids. The decision of the Board will be final. No bid may be withdrawn by any bidder for a period of thirty (30) days after bids are opened. Kelly King, Chairman Calhoun County School Board ATTEST: Tommy McClellan, Superintendent Calhoun County Schools Legal Notice The Calhoun County School Board proposes to introduce and amend policies for Calhoun County Schools as follows: ADMINISTRATIVE PROCEDURES ACT CALHOUN COUNTY SCHOOLS CHAPTER 5-STUDENTS CHAPTER 6-HUMAN RESOURCES Introducing and Amending Policy: Policy 5.14 Homeless Students Policy 5.64 Nutrition, Physical Fitness, and Wellness Policy 6.531 DROP Policy 6.81 Social Security Number Collection and Usage Policy 6.912 Terminal Sick Leave and Vacation Pay The entire proposals are available for viewing at the School Superintendent’s Office, Room G-20, Calhoun County Court House, Blountstown, Florida. A hearing will be held on the above policies in the Courthouse in Blountstown, Florida at the Regular School Board meeting on Tuesday, August 11, 2009 at 5:00 p.m. Kelly King, Chairperson Calhoun County School Board Attest: Wilson T. McClellan, Superintendent Calhoun County Schools Legal Notice IN THE CIRCUIT COURT OF THE 14TH JUDICIAL CIRCUIT IN AND FOR CALHOUN COUNTY, FLORIDA CASE NO.2009-0066-DR Bonnie Torres, Petitioner and Luis Torres, Respondent NOTICE OF ACTION FOR DISSOLUTION OF MARRIAGE To: Luis Torres Address: 1511 168th Street, Pembroke Pines, Fl. 33028 YOU ARE NOTIFIED that an action has been filed against you and that you are required to serve a copy of your written defenses, if any, to it on Bonnie Torres, whose address is P.O. Box 1003, Blountstown, FL 32424 on or before August 7, 2009, and file the original with the clerk of this Court at 20859 Central Ave., E., Room 130, Blountstown, FL 32424, before service on Petitioner or immediately thereafter. If you fail to do so, a default may be entered against you for the relief demanded in the petition. Copies of all court documents in this case, including orders, are available at the Clerk of the Circuit Court’s office. You may review these documents upon request. You must keep the Clerk of the Circuit Court’s office notified of your current address. (You may file Notice of Current Address, Florida Supreme Court Approved Family Law form 12.915.) Future papers in this lawsuit will be mailed to the address on record at the clerk’s office. WARNING: Rule 12.285, Florida Family Law Rules of Procedures, requires certain automatic disclosure of documents and information. Failure to comply can result in sanctions, including dismissal or striking of pleadings. Dated this July 2, 2009. Ruth W. Attaway, Clerk of the Circuit Court Legal Notice IN THE CIRCUIT COURT OF THE 14TH JUDICIAL CIRCUIT IN AND FOR CALHOUN COUNTY, FLORIDA CASE NO.2009-0163-DR Gloria Jean Juarez, Petitioner and Benito Gutierrez Juarez, Respondent NOTICE OF ACTION FOR DISSOLUTION OF MARRIAGE To: Benito Gutierrez Juarez, Address: P.O. Box 280053, Tampa, FL 33682 YOU ARE NOTIFIED that an action has been filed against you and that you are required to serve a copy of your written defenses, if any, to it on Gloria Jean Juarez, whose address is P.O. Box 244, Blountstown, FL 32424 on or before August 7, 2009, and file the original with the clerk of this Court at 20859 Central Ave., E., Room 130, Blountstown, FL 32424, before service on Petitioner or immediately thereafter. If you fail to do so, a default may be entered against you for the relief demanded in the petition. Copies of all court documents in this case, including orders, are available at the Clerk of the Circuit Court’s office. You may review these documents upon request. You must keep the Clerk of the Circuit Court’s office notified of your current address. (You may file Notice of Current Address, Florida Supreme Court Approved Family Law form 12.915.) Future papers in this lawsuit will be mailed to the address on record at the clerk’s office. WARNING: Rule 12.285, Florida Family Law Rules of Procedures, requires certain automatic disclosure of documents and information. Failure to comply can result in sanctions, including dismissal or striking of pleadings. Dated this July 8, 2009. Ruth W. Attaway, Clerk of the Circuit Court Legal Notice Public Auction Mallory Towing and Recovery Inc. will hold a public auction on, August 7, 2009 at 2:00 (P.M.) on a: 1994 Ford, Ranger Super, TK, Green in Color Vin#1FTCR14X2RPC56404 Auction will be held at Mallory Towing and Recovery Inc. at 17311 NE Pear Street in Blountstown FL., 850-674-2869. Mallory Towing and Recovery Inc. reserves the right to reject any and all bids. Legal Notice CALHOUN COUNTY PROJECT # 014.140 CHIPOLA ROAD IMPROVEMENTS NOTICE TO RECEIVE SEALED BIDS The Calhoun County Board of County Commissioners will receive sealed bids from any qualified person, company or corporation interested in constructing the following project: CALHOUN COUNY CHIPOLA ROAD IMPROVEMENTS Plans and specifications can be obtained at Preble-Rish, Inc., 20684 Central Ave. East, Blountstown, FL 32424; (850) 674-3300. The bid must conform to Section 287.133(3) Florida Statutes, on public entity crimes. Completion date for these projects will be 180 days from the date of the Notice to Proceed presented to the successful bidder. Liquidated damages for failure to complete the project on the specified date will be set at $500.00 per day. All bidders must be pre-qualified with Florida Department of Transportation per Section 2-1 f the FDOT Standards and Specifications of Road and Bridge Construction, latest edition. Please indicate on the envelope that this is a sealed bid, the bid number and what the bid is for. Bids will be received until 2:00 p.m. (C.T.), on August 18, 20 09 , at the Calhoun County Clerk’s Office, Calhoun County Courthouse, 20859 Central Avenue East, Room 130, Blountstown, Florida 32424, and will be opened and read aloud on August 18, 20 09 , at 5:00 p.m.(C.T.). Cost for Plans and Specifications will be $ 100.00 per set and is non-refundable. Checks should be made payable to PREBLE-RISH, INC. The Board of County Commissioners reserves the right to waive informalities in any bid, to accept and/or reject any or all bids, and to accept the bid that in their judgment will be in the best interest of Calhoun County. Legal Notice NOTICE OF POTENTIAL VOTER REGISTRATION INELIGIBILITY   Pursuant to Section 98.075, Florida Statutes, and information provided by the State of Florida Division of Elections, the Calhoun County Supervisor of Elections hereby provides notice that the following individuals are potentially ineligible to be registered to vote in Calhoun County and may be declared ineligible to vote if they fail to contact the Supervisor’s Office within 30 days after the date this notice is published:   Tommy W. Bailey, 5717 SW SR 73, Kinard, FL 32449 Julia Ann Crowson, 21110 NE Cochran Lane, Blountstown, FL 32424 Joseph M. Lambeth, 14619 SW CR 275, Blountstown, FL 32424   An individual who fails to respond to this notice may also have his or her name removed from the statewide voter registration system. Any individual listed may contact the Supervisor’s Office no later than 30 days after the date this notice is published to receive information regarding the basis for the potential ineligibility and the procedure to resolve the matter. Should a listed individual need further assistance, he or she should contact the Calhoun County Supervisor of Elections Office at (850) 674-8568. Published July 29, 2009, as required by Florida law.   MARGIE C. LARAMORE CALHOUN COUNTY SUPERVISOR OF ELECTIONS 20859 CENTRAL AVE. EAST, RM. G-10 BLOUNTSTOWN, FL 32424 PHONE  (850) 674-8568 Legal Notice IN THE CIRCUIT COURT OF THE FOURTEENTH JUDICIAL CIRCUIT OF THE STATE OF FLORIDA, IN AND FOR CALHOUN COUNTY CIVIL DIVISION CASE NO: 02009-CA-61 TAYLOR, BEAN & WHITAKER MORTGAGE CORP., Plaintiff, -vs- TERESA BODIFORD, THE UNKNOWN SPOUSE OF TERESA BODIFORD, WILEY D. TOLBERT; STEVEN BODIFORD; THE UNKNOWN SPOUSE OF STEVEN BODIFORD; OF LIVING, INCLUDING ANY UNKNOWN SPOUSE OF SAID DEFENDANT(S), IF REMARRIED, AND IF DECEASED, THE RESPECTIVE UNKNOWN HEIRS, DEVISEES, GRANTEES, ASSIGNEES, CREDITORS, LIENORS, AND TRUSTEES, AND ALL OTHER PERSONS CLAIMING BY, THROUGH, UNDER OR AGAINST THE NAMED DEFENDANT(S); UNKNOWN TENANT #1; UNKNOWN TENANT #2. Defendant(s) NOTICE OF SALE Notice is hereby given that, pursuant to a Final Summary Judgment of Foreclosure entered in the above-styled cause, in the Circuit Court of Calhoun County Florida, I will sell the property situate in Calhoun County, Florida, described as: Begin at the Northwest Corner of the Southwest 1/4 of the Northwest 1/4 of Section 4, Township 2 North, Range 9 West, Calhoun County, Florida; thence run East 830 feet; thence run south 530 feet; thence run West 830 feet; thence north 530 feet; back to the POINT OF BEGINNING. A/K/A 14893 NW Sam Duncan Road Altha, FL 32421 at public sale, to the highest and best bidder, for cash, Calhoun County Courthouse, 20859 SE Central Avenue East, Blountstown, FL 32424 at 11:00 A.M. CST on August 20, 2009. DATED at CALHOUN County this 20th day of July, 2009. Any person claiming an interest in the surplus from the sale, if any, other than the property owner as of the date of the lis pendens, must filer a claim within 60 days after the sale. WITNESS my hand and seal of this court on the 13th day of May, 2009. Ruth W. Attaway Clerk of Court In accordance with the American with Disabilities Act of 1990, persons needing accommodation to participate in this proceeding should contact the ASA Coordinator no later than seven (7) days prior to the proceedings. If hearing impaired, please call (800) 955-9771 (TDD) or (800) 59-8770 (voice), via Florida Relay Service Law Offices of Daniel C. Consuegra 9204 King Palm Drive Tampa, FL 33619-1328 Tel: (813) 915-8660 Fax: (813) 915-0559 Attorney for Plaintiff Legal Notice CITY OF BLOUNTSTOWN – MISCELLANEOUS STRIPING NOTICE TO RECEIVE SEALED BIDS The City of Blountstown will receive sealed bids from any qualified person, company or corporation interested in constructing: CITY OF BLOUNTSTOWN – MISCELLANEOUS STRIPING This project shall consist of miscellaneous striping on various roads within the City of Blountstown. The RFP package can be obtained at Blountstown City Hall located at 20591 Central Avenue West, Blountstown Florida 32424 (850) 674-5488. The bid must conform to Section 287.133(3) Florida Statutes, on public entity crimes. Completion date for these projects will be 90 days from the date of the Notice to Proceed presented to the successful bidder. Liquidated damages for failure to complete the project on the specified date will be set at $200.00 per day. Please indicate on the envelope that this is a sealed bid, the bid number and what the bid is for. Bids will be received until 2:00 p.m. Eastern Time, on September 8 , 2009, at the Blountstown City Hall located at 20591 Central Avenue West, Blountstown Florida 32424 (850) 674-5488, and will be opened and read aloud on September 8 , 2009, at 6:00 p.m. Central Time. The public is invited to attend. Cost for Plans and Specifications will be $25.00 per set and is non-refundable. Checks should be made payable to the City of Blountstown. The City of Blountstown reserves the right to waive informalities in any bid, to accept and/or reject any or all bids, and to accept the lowest responsive and responsible bid. If you have any questions, please call James Woods at (850) 674-5488.

Be First to Comment

    Leave a Reply

    Your email address will not be published.