Press "Enter" to skip to content

Legal Notices For 07-09-09

Legal Notices For 07-09-09 Legal Notice INVITATION TO BID Sealed bids will be received by the Calhoun County School Board until 5:00 P.M., CT, Tuesday, July 14, 2009, for the purchase of the following: Bread Products for use in the school cafeterias for the bid period of August 1, 2009 through June 30, 2010. Any additional information or bid forms required may be obtained at the School Lunch Office, 16651 SE River Street, Blountstown, Florida. Each bidder submitting a bid must use bid forms, otherwise bids will not be considered. Any bid submitted after the specified hour and date will not be opened or considered. The Board accepts no responsibility for mailed proposals that arrive at the School Lunch Office after the above stated time, even though the envelope may reflect a postmark prior to the above date. The Board reserves the right to accept or reject any or all bids. The decision of the Board will be final. No bid may be withdrawn by any bidder for a period of thirty (30) days after bids are opened. Timothy G. Smith, Chairman Calhoun County School Board ATTEST: Tommy McClellan, Superintendent Calhoun County Schools Legal Notice INVITATION TO BID Sealed bids will be received by the Calhoun County School Board until 5:00 P.M., CDT, Monday, August 3, 2009, for the purchase of the following: LP Gas for use in lunchrooms and schools of Calhoun County. Any additional information or bid forms required may be obtained at the Office of the School Superintendent, 20859 Central Ave. E., Rm. G-20, Blountstown, Florida. Bid forms must be used by each bidder submitting a bid. Otherwise bids will not be considered. Any bid submitted after the specified hour and date will not be opened or considered. The Board accepts no responsibility for mailed proposals that arrive at the Superintendent’s Office after the above stated time, even though the envelope may reflect a postmark prior to the above date. The Board reserves the right to accept or reject any or all bids. The decision of the Board will be final. No bid may be withdrawn by any bidder for a period of thirty (30) days after bids are opened. Kelly King, Chairman Calhoun County School Board ATTEST: Tommy McClellan, Superintendent Calhoun County Schools Legal Notice CALHOUN COUNTY BOARD OF COUNTY COMMISSIONERS NOTICE TO BIDDERS Sealed proposals, in triplicate, will be received by the Calhoun County Board of County Commissioners until 12:00 Noon, local time, July 21 2009, local time at Calhoun County Board of County Commissioner, Clerk of Court’s Office, 20859 Central Avenue East, Room 130, Blountstown, Florida 32424. All proposals received will be publicly opened and read aloud at the Calhoun County Board of County Commissioners meeting on the same date. Bidders are invited to submit proposals for: CONSTRUCT T-HANGAR AT THE CALHOUN COUNTY AIRPORT Bidders are invited to submit Proposals for this work on the Proposal Forms provided. Other proposal forms will not be accepted. The Complete examination and understanding of the Contract Documents consisting of the Plans and Specifications, and all addenda or other revisions and Site of the proposed work is necessary to properly submit a Proposal. Contract Documents consisting of the Plans and Specifications, and all addenda or other revisions are available for examination or may be obtained from the offices of the URS Corporation, 1367C South Railroad Avenue, Chipley, Florida 32428, Phone (850) 638-8700, Fax (850) 638-0220. There is a $100.00 charge for the plans and specifications. This cost is non refundable. A Bid Bond in the form as bound in the Contract Documents or Certified Check in the amount of not less than five percent (5%) of the total amount bid must accompany each Bid. Successful Bidder shall be required to execute and to provide a Payment Bond and Performance Bond each in an Amount of not less than one hundred percent (100%) of the total value of the Contract awarded to him with a satisfactory surety or sureties for the full and faithful performance of the work. The Calhoun County Board of County Commissioners, in accordance with Title VI of the Civil Rights Act of 1964 (42 U.S.C. 2000d) and 49 CFR, Part 26 Participation by Disadvantaged Business enterprises in Department of Transportation Programs, hereby notifies all bidders that it will affirmatively ensure that disadvantaged business enterprises are afforded full opportunity to submit bids in response to this invitation and will not be discriminated against on the grounds of race, color, sex or national origin in consideration for an award. No bid may be withdrawn after closing time for the receipt of Proposals for a period of one hundred twenty (120) days. The Calhoun County Board of County Commissioners reserves the right to waive any informalities or irregularities in or reject any or all bids and to award or refrain from awarding the Contract for the Work. Dated: June 25, 2009 By Calhoun County Board of County Commissioners Legal Notice INVITATION TO BID Sealed bids will be received by the Calhoun County Sheriff’s Office until July 17, 2009 at 3:00 p.m. CT, for the purchase of the following: 2002 Ford F-150 Supercrew 4X4, Mileage: 107,184 Vin# 1FTRW08L42KA10686 Minimum Bid: $8,000.00 Any additional information required may be obtained by contacting Lt. Adam Terry at the Calhoun County Sheriff’s Office at (850) 643-7968 or (850) 674-5049. Any bids submitted after the specified hour and date will not be opened or considered. The Calhoun County Sheriff’s Office accepts no responsibility for mailed proposals that arrived at the Sheriff’s Office after the above stated time even though the envelope may reflect a postmarked prior to the above date. Bids will be accepted in the Administrative office located at 20776 Central Avenue East, Suite #2, Blountstown, Florida. The Calhoun County Sheriff’s Office reserves the right to accept or reject any or all bids. This vehicle is sold “AS IS” “WHERE IS” with no warranty. This vehicle can be seen at the Calhoun-Liberty Employees Credit Union, 17394 Charlie Johns Street, Blountstown, Florida. Legal Notice NOTICE OF POTENTIAL VOTER REGISTRATION INELIGIBILITY   Pursuant to Section 98.075, Florida Statutes, and information provided by the State of Florida Division of Elections, the Calhoun County Supervisor of Elections hereby provides notice that the following individuals are potentially ineligible to be registered to vote in Calhoun County and may be declared ineligible to vote if they fail to contact the Supervisor’s Office within 30 days after the date this notice is published:   Jeannette Addison, 21461 SE Ridge Ave., Blountstown, FL 32424 Miguel A. Alejos, 19955 NE CR 274, Altha, FL 32421 James R. Argyros, 25339 NW Walter Potts Rd., #K, Altha, FL 32421 Jennifer S. Comiskey, 17225 NW Angle St., Blountstown, FL 32424 John S. Fleck, 15952 NE Chipola St., Altha, FL 32421 Kristi L. Greer, 19339 SW Hidden Creek Rd., Lot 8, Blountstown, FL 32424 Mark Guilford, 19217 SW Matthew Wood Rd., Blountstown, FL 32424 Becky Jacobs, 274-A, RR1, Altha, FL 32421 Heather M. Kozma, 22476 NW Pine Ln., Fountain, FL 32438 Wayne A. Luke, 15732 NW Smith St., Altha, FL 32421 Brandy Petty, 6217 NW Camp Head Rd., Altha, FL 32421 Timothy S. Robinson, 23044 NW Watson Rd., Altha, FL 32421 Jack Smith, 14988 SE Redhorse Sucker Rd., Blountstown, FL 32424   An individual who fails to respond to this notice may also have his or her name removed from the statewide voter registration system. Any individual listed may contact the Supervisor’s Office no later than 30 days after the date this notice is published to receive information regarding the basis for the potential ineligibility and the procedure to resolve the matter. Should a listed individual need further assistance, he or she should contact the Calhoun County Supervisor of Elections Office at (850) 674-8568. Published July 8, 2009, as required by Florida law. MARGIE C. LARAMORE CALHOUN COUNTY SUPERVISOR OF ELECTIONS 20859 CENTRAL AVE. EAST, RM. G-10 BLOUNTSTOWN, FL 32424 PHONE  (850) 674-8568 Legal Notice REQUEST FOR PROPOSAL (QUALIFICATIONS AND PRICING) For REAL ESTATE APPRAISAL SERVICES FOR THE CALHOUN COUNTY BOARD OF COUNTY COMMISSIONERS All responses submitted to this solicitation should be addressed to and received no later than 3:00 p.m., July 20, 2009 at: CALHOUN COUNTY CLERK OF THE COURT 20859 Central Avenue East, Room 130 Blountstown, FL 32424 Phone: (850) 674-4545 Attention: Request for Proposal – Real Estate Appraiser for the Calhoun County Board of County Commissioners NOTICE OF REQUEST FOR PROPOSALS NOTICE IS HEREBY GIVEN TO PROSPECTIVE PROPOSERS that on July 21, 2009 at 5:00 P.M. at the Calhoun County Courthouse Annex, the Board of County Commissioners of Calhoun County, Florida, will open sealed proposals for the following: Real Estate Appraiser The County is seeking sealed proposals for Real Estate Appraisal Services for the Calhoun County Board of County Commissioners. To be eligible for submission/consideration, proposers must: • Be a citizen of the United States of America. • Be an appraiser licensed by the State of Florida. • Been previously qualified as an expert witness by a court of competent jurisdiction in the State of Florida. • Not be a person who represents property owners in any administrative or judicial review of property tax issues in Calhoun County, Florida. • Hold qualifications as a MAI appraiser by the Appraisal institute. • Be able to submit appraisals sufficient to meet the legal requirements for Florida Statute 73.015 for the four parcels for use in an eminent domain proceeding by Calhoun County Florida within three weeks from the notice of award. Project overview: Calhoun County is seeking to improve the roadway and drainage structures on a rural roadway named “Laramore Road”. In doing so, there are four parcels, which must be obtained by eminent domain. The legal description of these four parcels as well as a title search and a sketch survey of the parcels is available upon request from the County Administrator, Don A. “Sonny” O’Bryan at 850-674-8075. The proposal submitted shall include a statement addressing the qualifications of the proposed firm, the compensation required to prepare and submit the four appraisals including any consultation with the County attorney necessary to submit an offer to four land owners pursuant to Florida Statute 73.015 and the hourly rate for any additional services including but not limited to expert testimony, trial preparation and other expenses. Proposers must submit two (2) original responses marked “Original” in a sealed envelope clearly marked on the outside with the Proposer’s name and “Sealed Proposal for Real Estate Appraisers services”, addressed and delivered to Clerk of the Court of Calhoun County, Florida 20859 Central Avenue East, Room 130 Blountstown, FL 32424 Phone: (850) 674-4545 All proposals must be received by the Clerk of the Court on or before 3:00 P.M. on July 20, 2009. Any proposals received after this date and time will be automatically rejected. Materials may be delivered by Certified Mail, Return Receipt Requested, hand-delivered or couriered. Faxed or e-mailed proposals will be automatically rejected. Hand delivered Proposals may request a receipt. If sent by mail or by courier, the above-mentioned envelope shall be enclosed in another envelope addressed to the entity and address stated above. All proposals shall remain valid for a period of ninety (90) days beyond the deadline for submission and may be extended beyond that time by mutual agreement. The Board will automatically reject the response of any person or affiliate who appears on the convicted vendor list prepared by the Department of Management Services, State of Florida, under Sec. 287.133(3)(d), Florida Statute (1997). Calhoun County declares that all or portions of the documents and work papers and other forms of deliverables pursuant to this request shall be subject to reuse by the County. Contract award will be by the Calhoun County Board of County Commissioners to the entity whose response is deemed to be in the best interest of the Calhoun County Board of County Commissioners. The Board reserves the right to reject any and all proposals, to waive informalities in any or all proposals, to re-advertise for proposals, and to separately accept or reject any item or items and to award and/or negotiate a contract in the best interest of the Calhoun County Board of County Commissioners. Publication dates: July 8, 15, 2009 Legal Notice IOLA ROAD CULVERT REPLACEMENT PROJECT # 14.132 NOTICE TO RECEIVE SEALED BIDS The Calhoun County Board of County Commissioners will receive sealed bids from any qualified person, company or corporation interested in constructing the following project: IOLA ROAD CULVERT REPLACEMENT Plans and specifications can be obtained at Preble-Rish, Inc., 324 Marina Drive, Port St. Joe, Florida 32456, (850) 227-7200. The bid must conform to Section 287.133(3) Florida Statutes, on public entity crimes. The project consists of removing and replacing an existing cross drain under Iola Road and replacing asphalt at the culvert site. Completion date for this project will be 60 days from the date of the Notice to Proceed presented to the successful bidder. Liquidated damages for failure to complete the project on the specified date will be set at $200.00 per day. Please indicate on the envelope that this is a sealed bid, the bid number and what the bid is for. Bids will be received until 2:00 p.m. (CT), on Tuesday, July 21, 2009, at the Calhoun County Clerk’s Office, Calhoun County Courthouse, 20859 Central Avenue East, Room 130, Blountstown, Florida 32424, and will be opened and read aloud on Tuesday, July 21,2009, at 5:00p.m. (CT). Cost for Plans and Specifications will be $50.00 per set and is non-refundable. Checks should be made payable to PREBLE-RISH, INC. The Board of County Commissioners reserves the right to waive informalities in any bid, to accept and/or reject any or all bids, and to accept the bid that in their judgment will be in the best interest of Calhoun County. If you have any questions, please call Matt Carpenter at (850) 643-2771. Legal Notice IN THE CIRCUIT COURT FOR CALHOUN COUNTY, FLORIDA PROBATE DIVISION FILE NO.: 09-10PR IN RE: ESTATE OF: MARSHA HARPOOL, Deceased. NOTICE OF CREDITORS (Summary Administration) TO ALL PERSONS HAVING CLAIMS OR DEMANDS AGAINST THE ABOVE ESTATE: You are hereby notified that an Order of Summary Administration has been entered in the estate of MARSHA F. HARPOOL, deceased, File Number 09-10PR; by the Circuit Court for Calhoun County, Florida. Probate Division; the address of which is 20859 East Central Avenue, Blountstown, Florida 32424; that the decedents’ date of death was February 22, 2008; and that the name and address of those to whom it has been assigned by such order are: Adam Harpool, 430 Atwood Street, Pittsburgh, PA 15213. TO ALL INTERESTED PERSONS ARE NOTIFIED THAT: All creditors of the estate of the decedent and persons having claims or demands against the estate of the decedent other than those for whom provision for payment was made in the Order of Summary Administration must file their claims with this COURT WITHIN THREE (3) MONTHS AFTER THE DATE OF THE FIRST PUBLICATION OF THIS NOTICE. ALL CLAIMS AND DEMANDS NOT SO FILED WILL BE FOREVER BARRED. NOTWITHSTANDING THE TIME PERIOD SET FORTH ABOVE, ANY CLAIM FILED TWO (2) OR MORE YEARS AFTER THE DECEDENT’S DATE OF DEATH IS BARRED. THE DATE OF FIRST PUBLICATION OF THIS NOTICE IS JULY 8, 2009. Person Giving Notice: Adam Harpool Attorney for Person Giving Notice J. DAVID HOUSE 16865 S.E. RIVER STREET BLOUNTSTOWN, FLORIDA 32424 (850) 674-5481 FLORIDA BAR #282359 Legal Notice CALHOUN COUNTY 2008-2009 CDBG PROJECT PROJECT # 14.135 NOTICE TO RECEIVE SEALED BIDS The Calhoun County Board of County Commissioners will receive sealed bids from any qualified person, company or corporation interested in constructing: CALHOUN COUNTY 2008-2009 CDBG PROJECT Plans and specifications can be obtained at Preble-Rish, Inc., 324 Marina Drive, Port St. Joe, Florida 32456, (850) 227-7200. The bid must conform to Section 287.133(3) Florida Statutes, on public entity crimes. This project is a new construction roadway paving project which consists of grading, shaping, and compacting limerock, reworking shoulders, placing asphalt, and striping the roadway. All bidders shall be pre-qualified with the Florida Department of Transportation per Section 2-1 of the F.D.O.T. Standard Specifications for Road and Bridge Construction, latest edition. Completion date for these projects will be 120 days from the date of the Notice to Proceed presented to the successful bidder. Liquidated damages for failure to complete the project on the specified date will be set at $200.00 per day. Please indicate on the envelope that this is a sealed bid, the bid number and what the bid is for. Bids will be received until 2:00 p.m. (C.T.), on Tuesday, July 21 , 20 09 , at the Calhoun County Clerk’s Office, Calhoun County Courthouse, 20859 Central Avenue East, Room 130, Blountstown, Florida 32424, and will be opened and read aloud on Tuesday, July 21 , 20 09 , at 5:00 p.m.(C.T.). Cost for Plans and Specifications will be $ 50.00 per set and is non-refundable. Checks should be made payable to PREBLE-RISH, INC. The Board of County Commissioners reserves the right to waive informalities in any bid, to accept and/or reject any or all bids, and to accept the bid that in their judgment will be in the best interest of Calhoun County. If you have any questions, please call Matt Carpenter at (850) 643-2771 or carpenterm@preble-rish.com. Legal Notice IN THE CIRCUIT COURT OF THE FOURTEENTH JUDICIAL CIRCUIT OF THE STATE OF FLORIDA, IN AND FOR CALHOUN COUNTY CIVIL DIVISION CASE NO: 07-2009-CA-000118 CITIFINANCIAL EQUITY SERVICES, INC. Plaintiff, -vs- PHILIP B. KNIGHT; UNKNOWN SPOUSE OF PHILIP B. KNIGHT; DANIKA LEE KNIGHT; UNKNOWN SPOUSE OF DANIKA LEE KNIGHT; IF LIVING, INCLUDING ANY UNKNOWN SPOUSE OF SAID DEFENDANT(S), IF REMARRIED, AND IF DECEASED, THE RESPECTIVE UNKNOWN HEIRS, DEVISEES, GRANTEES, ASSIGNEES, CREDITORS, LIENORS, AND TRUSTEES, AND ALL OTHER PERSONS CLAIMING BY, THROUGH, UNDER OR AGAINST THE NAMED DEFENDANT(S); UNKNOWN TENANT #1; UNKNOWN TENANT #2; Defendant. NOTICE OF ACTION PHILIP B. KNIGHT; UNKNOWN SPOUSE OF PHILIP B. KNIGHT; DANIKA LEE KNIGHT; UNKNOWN SPOUSE OF DANIKA LEE KNIGHT; IF LIVING, INCLUDING ANY UNKNOWN SPOUSE OF SAID DEFENDANT(S), IF REMARRIED, AND IF DECEASED, THE RESPECTIVE UNKNOWN HEIRS, DEVISEES, GRANTEES, ASSIGNEES, CREDITORS, LIENORS, AND TRUSTEES, AND ALL OTHER PERSONS CLAIMING BY, THROUGH, UNDER OR AGAINST THE NAMED DEFENDANT(S); UNKNOWN TENANT #1; UNKNOWN TENANT #2; Whose residence are/is unknown. YOU ARE HEREBY required to file your answer or written defenses, if any, in the above proceeding with the Clerk of this Court, and to serve a copy thereof upon the plaintiff’s attorney, Law Offices of Daniel C. Consuegra, 9204 King Palm Drive, Tampa, FL 33619-1328, telephone (813) 915-8660, facsimile (813) 915-0559, within thirty days of the first publication of this Notice, the nature of this proceeding being a suit for foreclosure of mortgage against the following described property, to wit: BEGIN AT A STAKE ON EAST BOUNDARY OF PEAR STREET AT INTERSECTION OF SOUTH BOUNDARY OF NE 1/4 OF SW 1/4, SECTION 33, TOWNSHIP 1 NORTH, RANGE 8 WEST, AND RUN SOUTH 113 1/2 FEET FOR POINT OF BEGINNING, THENCE RUN EAST 140 FEET, THENCE SOUTH 88 1/2 FEET, THENCE WEST 140 FEET, THENCE NORTH 88 1/2 FEET TO POINT OF BEGINNING. A/K/A 16227 PEAR STREET SE BLOUNTSTOWN, FL 32424 If you fail to file your answer or written defenses in the above proceeding, on plaintiff’s attorney, a default will be entered against you for the relief demanded in the Complaint or Petition. DATED at CALHOUN County this 2nd day of July, 2009. Ruth W. Attaway Clerk of Court In accordance with the American with Disabilities Act of 1990, persons needing accommodation to participate in this proceeding should contact the ASA Coordinator no later than seven (7) days prior to the proceedings. If hearing impaired, please call (800) 955-9771 (TDD) or (800) 59-8770 (voice), via Florida Relay Service

Be First to Comment

    Leave a Reply

    Your email address will not be published.