Press "Enter" to skip to content

Legal Notices For 05-27-10

Legal INVITATION TO BID Sealed bids will be received by the Calhoun County School Board until 4:00 P.M., CDT, Tuesday, June 8, 2010, for the purchase of the following: LP Gas for use in lunchrooms and schools of Calhoun County. Gasoline and Diesel for use in the operation of public vehicles, school buses and school plants. Any additional information or bid forms required may be obtained at the Office of the School Superintendent, 20859 Central Ave. E., Rm. G-20, Blountstown, Florida. Bid forms must be used by each bidder submitting a bid. Otherwise bids will not be considered. Any bid submitted after the specified hour and date will not be opened or considered. The Board accepts no responsibility for mailed proposals that arrive at the Superintendent’s Office after the above stated time, even though the envelope may reflect a postmark prior to the above date. The Board reserves the right to accept or reject any or all bids. The decision of the Board will be final. No bid may be withdrawn by any bidder for a period of thirty (30) days after bids are opened. Kelly King, Chairman Calhoun County School Board ATTEST: Wilson T. McClellan, Superintendent Calhoun County Schools Legal Notice INVITATION TO BID Sealed bids will be received by the Calhoun County School Board until 4:30 P.M., CT, Tuesday, June 8, 2010, for the purchase of the following: Bread Products (hamburger buns, wiener buns, sub buns and sandwich loafs) for use in the school cafeterias for the bid period of Jly 1, 2010 – June 30, 2011. Any additional information or bid forms required may be obtained at the Office of the Superintendent, 20859 Central Avenue East, RM-G20, Blountstown, Florida 32424. Each bidder submitting a bid must use bid forms, otherwise bids will not be considered. Any bid submitted after the specified hour and date will not be opened or considered. The Board accepts no responsibility for mailed proposals that arrive at the Superintendent’s Office after the above stated time, even though the envelope may reflect a postmark prior to the above date. The Board reserves the right to accept or reject any or all bids. The decision of the Board will be final. No bid may be withdrawn by any bidder for a period of thirty (30) days after bids are opened. Kelly King, Chairman Calhoun County School Board ATTEST: Wilson T. McClellan, Superintendent Calhoun County Schools Legal Notice IN THE CIRCUIT COURT OF THE FOURTEENTH JUDICIAL CIRCUIT OF FLORIDA IN AND FOR CALHOUN COUNTY CASE NO.: 10-36-CA TYNDALL FEDERAL CREDIT UNION, Plaintiff, -vs- SAMUEL J. EDWARDS, and wife, SYLVIA A. EDWARDS, Defendants. NOTICE OF SALE NOTICE IS HEREBY GIVEN, that the undersigned Clerk of the Circuit Court of Calhoun County, Florida, pursuant to the Final Summary Judgment of Foreclosure, entered in this cause, will sell at the door of the Calhoun County Courthouse in Blountstown, Florida, at 11:00 a.m. (CT), on the 15th day of July, 2010, the following described real property lying and being in Calhoun County, Florida, to-wit: Commence at the Southeast Corner of the Northeast Quarter of the Southwest Quarter of Section 36, Township 1 North, Range 10 West, Calhoun County, Florida and run thence North 89 degrees 42 minutes 47 seconds West, a distance of 75.00 feet to the Southeast Corner of lands described in Official Records Book 199 at Page 331 of the Public Records of Calhoun County, Florida; thence North 00 degrees 17 minutes 13 seconds East along the Easterly boundary of said lands, a distance of 25.93 feet to a point on the Northerly right of way boundary of State Road No. 20; thence North 89 degrees 22 minutes 32 seconds West along said Northerly right of way boundary, a distance of 7.08 feet to the southerly projection of an old fence; thence North 00 degrees 44 minutes 19 seconds East along said southerly projection, said fence and the northerly projection of said fence, a distance of 184.03 feet to the Northerly boundary of the aforesaid lands descried in Official Records Book 199 at Page 331; thence North 89 degrees 42 minutes 47 seconds West along the Northerly boundary of said lands, a distance of 129.37 feet; thence South 00 degrees 17 minutes 13 seconds West along the Westerly boundary of said lands, a distance of 183.27 feet to the aforesaid Northerly right of way boundary; thence South 89 degrees 22 minutes 32 seconds East along said Northerly right of way boundary, a distance of 127.92 feet to the POINT OF BEGINNING. This Notice dated this 13th day of May, 2010. CLERK OF CIRCUIT COURT Legal Notice NOTICE OF FICTITIOUS NAME NOTICE UNDER THE FICTITIOUS NAME REGISTRATION LAW, F.S. SECTION 865.09(3)(d) IS HEREBY GIVEN that Paramount Healthcare, LLC, located at 17400 NW 5th Street, in the County of Calhoun, in the City of Blountstown, Florida, desires to engage in business under the fictitious name CareSouth Homecare Professionals this 21st day of May, 2010. Legal Notice PUBLIC AUCTION Mallory Towing and Recovery Inc., will hold a public auction on, June 10,2010 at 2:00 (P.M.) on a: 1994 Ford, PK, White in Color Vin #1FTCR10A8RTA26858 Auction will be held at Mallory Towing and Recovery Inc., at 18114 State Road 20 West in Blountstown, FL., 32424 Phone: 850-674-2869. Mallory Towing and Recovery Inc., reserves the right to reject any and all bids. Legal Notice BID NOTICE STATE HOUSING INITAITIVES “SHIP PROGRAM” The Calhoun Board of County Commissioners will accept sealed bids on behalf of its State Housing Initiatives Partnership “SHIP” Program for the rehab of houses and roof repairs until 12:00 p.m. local time on Tuesday, June 15, 2010. Bids may be delivered to the Clerk’s Office in the Calhoun County Courthouse, Blountstown, Florida 32424. Bids must arrive before deadline. Bids will be opened at 5:00 p.m. or as soon afterwards as possible. Bids must be sealed in an envelope marked “sealed bid for ship rehab” and identified by the name of the firm, and the date and time of the bid opening. A mandatory pre-bid conference will be held on Tuesday, June 8, 2010, at 9:00 a.m. local time in room 117 in the Calhoun County Building Department located on the 1st floor of the Calhoun County Courthouse. Bid sheets and specifications will be available at the meeting. It is the responsibility of the contractor to purchase all permits deemed necessary. Bidders must provide proof of general liability and workman’s compensation insurance in the bid package. The insurance must be in force at the time of the bid opening. As an alternative to providing workman’s compensation insurance, the prospective bidder shall provide proof of worker’s compensation exemption. Any person claiming to be exempt shall be subject to an on-the-job inspection for proof of exemption and license of all workers on job site. Minority contractors are encouraged to participate. Calhoun County is an equal opportunity jurisdiction. The Calhoun County Board of County Commissioners reserves the right to reject any and all bids and to waive any informality. The signing of the contract is contingent upon the approval of and/or release of funds by the Florida housing finance agency. Effective April 22, 2010 any contractor performing renovation, repair or painting on any pre 1978 built home will be required to be a certified firm and employ at least one certified lead renovator. CALHOUN COUNTY IS /AN EQUAL OPPORTUNITY/FAIR HOUSING COUNTY. Legal Notice WEST SHERRY AVENUE EWP PROJECT # 013.054 NOTICE TO RECEIVE SEALED BIDS The City of Blountstown will receive sealed bids from any qualified person, company or corporation interested in constructing: WEST SHERRY AVENUE EWP This project consists of the reinforced concrete slab construction, slope stabilization and drainage improvements. Plans and specifications can be obtained at Preble-Rish, Inc., 20684 Central Avenue East, Blountstown, Florida 32424, (850)674-3300. The bid must conform to Section 287.133(3) Florida Statutes, on public entity crimes. Bids will be received until 12:00 NOON CST, on Tuesday, June 8, 2010 at Blountstown City Hall, 20591 Central Avenue West, Blountstown, Florida 32424, and will be opened and read publicly on Tuesday, June 8, 2010 at 6:00 p.m. CST. All Bids shall be submitted in an envelope clearly marked “Sealed Bid – West Sherry Avenue”. Completion date for these projects will be 90 days from the date of the Notice to Proceed presented to the successful bidder. Liquidated damages for failure to complete the project on the specified date will be set at $750.00 per day. Please indicate on the envelope your company name, that this is a sealed bid, and the bid number. The original bid plus two (2) copies should be included. Cost for Plans and Specifications will be $ 75.00 per set and is non-refundable. Checks should be made payable to PREBLE-RISH, INC. The City of Blountstown reserves the right to waive informalities in any bid, to accept and/or reject any or all bids, and to accept the bid that in their judgment will be in the best interest of the City. If you have any questions, please call Donald Stanley at (850) 674-3300 or email at HYPERLINK “mailto:stanleyd@preble-rish.com” stanleyd@preble-rish.com. Legal Notice IN THE CIRCUIT COURT OF THE FOURTEENTH JUDICIAL CIRCUIT IN AND FOR CALHOUN COUNTY, FLORIDA CASE NO.: 2010:069DR IN RE: THE MARRIAGE OF: LINDA JEAN DICKENSON, Petitioner/Wife and CHARLES STEVEN DICKENSON, Respondent/Husband NOTICE OF ACTION TO: Charles Steven Dickenson Address, residence and domicile Unknown YOU ARE NOTIFIED that an action for dissolution of marriage has been filed and you are required to serve a copy of your written defenses, if any, on Petitioner’s attorney, J David House, 16865 SE River Street, Blountstown, Florida 32424, on or before June 16, 2010, and file the original with the Clerk of this Court either before service on Petitioners’ attorney or immediately thereafter; otherwise a default will be entered against you for the relief demanded in the Petition. Witness my hand and seal of this Court on this17th day of May, 2010. RUTH W. ATTAWAY

Be First to Comment

    Leave a Reply

    Your email address will not be published.