Press "Enter" to skip to content

Legal Notices for 05-24-12

Legal Notice INVITATION TO BID FUEL Sealed bids will be received by the Calhoun County School Board until 4:00 P.M., CDT, Thursday, June 14, 2012, for the purchase of the following: Gasoline and Diesel for use in the operation of public vehicles, school buses and school plants. LP Gas for use in lunchrooms and schools of Calhoun County. Any additional information or bid forms required may be obtained at the Office of the School Superintendent, 20859 Central Ave. E., Rm. G-20, Blountstown, Florida. Bid forms must be used by each bidder submitting a bid. Otherwise bids will not be considered. Any bid submitted after the specified hour and date will not be opened or considered. The Board accepts no responsibility for mailed proposals that arrive at the Superintendent’s Office after the above stated time, even though the envelope may reflect a postmark prior to the above date. The Board reserves the right to accept or reject any or all bids. The decision of the Board will be final. No bid may be withdrawn by any bidder for a period of thirty (30) days after bids are opened. Tim Smith, Chairman Calhoun County School Board ATTEST: Wilson T. McClellan, Superintendent Calhoun County Schools Legal Notice AMENDED NOTICE OF SHERIFF’S SALE NOTICE IS HEREBY GIVEN THAT PURSUANT TO A WRIT OF EXECUTION hereto issued out of the County Court, of Calhoun County, Florida, Case No. 2011-03-CC on March 14, 2012, in the matter of Carlos Romero Sanchez vs. Terry Vincent and Pine Straw of Northwest Florida, Inc., I, David L. Tatum, As Sheriff of Calhoun County, Florida, have levied upon all the right, title and interest of the defendant(s) personal property, to-wit: 2003 Chevrolet Pickup Truck VIN # 1GCHK24163E104334 I shall offer this property for sale, on the steps of the Calhoun County Courthouse, State of Florida, on the 12th day of June 2012, at the hour of 9:00 A.M. or as soon thereafter as possible. I will offer for sale all the said defendant(s), Terry Vincent and Pine Straw of Northwest Florida, Inc., right, title and interest in the aforesaid personal property, at public auction and will sell the same, subject to taxes, all prior liens, encumbrances and judgments, if any to the highest and best bidder for CASH IN HAND. The proceeds to be applied as far as may be to the payment of costs and the satisfaction of the above described execution. David L. Tatum Sheriff, Calhoun County Legal Notice IN THE CIRCUIT COURT FOR CALHOUN COUNTY, FLORIDA CIVIL ACTION CASE N0.: 2011-000267-CA REGIONS BANK, Plaintiffs, -vs- RONNIE PITTS a/k/a Ronnie W. Pitts, et al., Defendants NOTICE OF SALE NOTICE is hereby given that pursuant to a Final Judgment of Foreclosure, entered in the above-styled cause on April 17, 2012, in the Circuit Court of Calhoun County, Florida, the Clerk of Calhoun County will sell the property situated in Calhoun County, Florida described as: THE FOLLOWING REAL PROPERTY SITUATE IN THE COUNTY OF CALHOUN AND STATE OF FLORIDA, DESCRIBED AS FOLLOWS: A PARCEL OF LAND IN CALHOUN COUNTY, FLORIDA, AND BEING MORE PARTICULARLY DESCRIBED AS FOLLOWS: COMMENCING AT THE NE CORNER OF SECTION 11, TOWNSHIP 1 SOUTH, RANGE 10 WEST, SAID CORNER MARKED BY A CONCRETE MARKER, STAMPED WITH “W. K. DAUGHERTY, SURVEYOR, DODD BUILDING, LAKE CITY” AND THENCE NORTH 88° 27’ 59” WEST ALONG THE NORTH LINE OF SAID SECTION, 710.39 FEET TO THE POINT OF BEGINNING, THENCE NORTH 88° 27’59” WEST ALONG THE NORTH LINE OF SAID SECTION, IN REDDIN BRUNSON ROAD, 625.46 FEET, THENCE SOUTH 0° 35’ 12” WEST ALONG THE WEST LINE OF THE NE 1/4 OF THE NE 1/4 OF SAID SECTION, AND AN EXISTING PROPERTY LINE FENCE ALONG THE EAST SIDE OF SAID ROAD, 1352.23 FEET, TO THE SW CORNER OF SAID FORTY; THENCE SOUTH 88° 09’ 02” EAST ALONG THE SOUTH LINE OF SAID FORTY AND AN EXISTING PROPERTY LINE FENCE, 214.83 FEET TO THE WESTERLY SIDE OF FLORIDA STATE ROAD NO. 73, THENCE NORTH 34° 36’ EAST ALONG THE SIDE OF SAID ROAD, 1089.69 FEET, THENCE NORTH 88° 27’ 59” WEST 492.70 FEET; THENCE NORTH 34° 36” EAST, 525.0 FEET, TO THE POINT OF BEGINNING, SAID LAND BEING IN THE NE 1/4 OF THE NE 1/4 OF SECTION 11, TOWNSHIP 1 SOUTH, RANGE 10 WEST. SUBJECT TO THE PUBLIC EASEMENT FOR REDDIN BRUNSON ROAD. LESS AND EXCEPT A PORTION THEREOF CONVEYED IN OFFICIAL RECORDS BOOK 163, PAGE 578, OF THE PUBLIC RECORDS OF CALHOUN COUNTY, FLORIDA. The street address of which is 16342 SW State Road 73, Clarksville, Florida 32430. at a Public Sale to the highest bidder, for cash, except as set forth hereinafter, on May 31, 2012, at 11:00 a.m. (Central Time), on the front steps of the Calhoun County Courthouse, located at 20859 East Central Avenue, Blountstown, Florida 32424, in accordance with Chapter 45, Florida Statutes. Dated: April 18, 2012. Any person claiming an interest in the surplus funds from the sale, if any, other than the property owner, as of the date of the Lis Pendens, must file a claim within 60 days after the sale. RUTH W. ATTAWAY Clerk of the Circuit Court, Calhoun County, Florida Legal Notice IN THE CIRCUIT COURT FOR CALHOUN COUNTY, FLORIDA PROBATE DIVISION File No. 2012-24 PR DONALD WAYNE PORTER, a/k/a DONALD W. PORTER, a/k/a DON W. PORTER, and a/k/a WAYNE PORTER, Deceased. NOTICE TO CREDITORS The administration of the Estate of Donald Wayne Porter, a/k/a Donald W. Porter, a/k/a Don W. Porter, and a/k/a Wayne Porter, deceased, whose date of death was March 21, 2011, and whose Social Security Number is xxx-xx-3935, is pending in the Circuit Court for Calhoun County, Florida, Probate Division, File Number 2012-24 PR, the address of which is 20859 Central Avenue East, Room 130, Blountstown, Florida 32421. The name and address of the personal representative and the personal representative’s attorney are set forth below. All creditors of the decedent and other persons having claims or demands against decedent’s estate on whom a copy of this notice has been served must file their claims with this Court WITHIN THE LATER OF THREE (3) MONTHS AFTER THE DATE OF THE FIRST PUBLICATION OF THIS NOTICE OR THIRTY (30) DAYS AFTER THE TIME OF SERVICE OF A COPY OF THIS NOTICE ON THEM. All other creditors of the decedent and other persons having claims or demands against decedent’s estate must file their claims with this Court WITHIN THREE (3) MONTHS AFTER THE DATE OF THE FIRST PUBLICATION OF THIS NOTICE. ALL CLAIMS NOT FILED WITHIN THE TIME PERIODS SET FORTH IN SECTION 733.702 OF THE FLORIDA PROBATE CODE WILL BE FOREVER BARRED. NOTWITHSTANDING THE TIME PERIOD SET FORTH ABOVE, ANY CLAIM FILED TWO (2) YEARS OR MORE AFTER THE DECEDENT’S DATE OF DEATH IS BARRED. The date of first publication of this notice is May 16, 2012. PERSONAL REPRESENTATIVE: LUCRETIA LEATH PORTER 20542 NW Gaston Spivey Road Altha, Florida Attorney for Personal Representative: FRANK E. BONDURANT Florida Bar No: 0520330 BONDURANT AND FUQUA, P.A. 4450 Office Box 1508 Marianna, FL 32447 (850) 526-2263 Legal Notice NOTICE TO RECEIVE SEALED BIDS The Calhoun County Board of County Commissioners will receive sealed bids from any qualified person, company or corporation interested in constructing: 2012 CDBG DISASTER RECOVERY ROAD PAVING J W RACKLEY STREET FLOY B RACKLEY ROAD RUDOLF RACKLEY ROAD BOWDEN ROAD LEONARD VARNUM WEST MYERS DAIRY ROAD Plans and specifications can be obtained at Preble-Rish, Inc., 20684 Central Avenue East, Blountstown, FL 32424, (850) 674-3300. The bid must conform to Section 287.133(3) Florida Statutes, on public entity crimes. This project is a new construction roadway-paving project, which consists of grading, shaping, and compacting limerock base and reworking shoulders. All bidders shall be pre-qualified with the Florida Department of Transportation per Section 2-1 of the F.D.O.T. Standard Specifications for Road and Bridge Construction, 2010 edition for: HOT PLANT-MIXED BITUM. COURSES FLEXIBLE PAVING DRAINAGE Completion date for these projects will be 180 days from the date of the Notice to Proceed presented to the successful bidder. Liquidated damages for failure to complete the project on the specified date will be set at $200.00 per day. Please indicate on the envelope that this is a sealed bid, the bid number and what the bid is for. Bids will be received until 12:00 p.m. (C.T.), on Tuesday, _June 5, 2012, at the Calhoun County Clerk’s Office, Calhoun County Courthouse, 20859 Central Avenue East, Room 130, Blountstown, Florida 32424, and will be opened and read aloud on Tuesday, _June 5, 2012 at 2:00 p.m. (C.T.) Cost for Plans and Specifications will be $75.00 per set and is non-refundable. Checks should be made payable to PREBLE-RISH, INC. The Board of County Commissioners reserves the right to waive informalities in any bid, to accept and/or reject any or all bids, and to accept the bid that in their judgment will be in the best interest of Calhoun County. If you have any questions, please call Donald Stanley at (850) 674-3300 or stanleyd@preble-rish.com. Legal Notice INVITATION TO BID The Calhoun County School Board will receive sealed bids until 3:00 PM, CT, Thursday, June 14, 2012, for the purchase of the following: Milk Products (Low Fat and Fat Free Unflavored, Fat Free Flavored-Chocolate and Strawberry) for use in the school cafeterias for the bid period of July 1, 2012 – June 30, 2013. Bread Products (hamburger buns, wiener buns, sub buns and sandwich loafs) for use in the school cafeterias for the bid period of July 1, 2012 – June 30, 2013. Any additional information or bid forms required may be obtained at the Special Programs Office, 20448 NW Pennington Avenue, Blountstown, Florida 32424. Each bidder submitting a bid must use bid forms, otherwise bids will not be considered. Any bid submitted after the specified hour and date will not be opened or considered. The Board accepts no responsibility for mailed proposals that arrive at the Superintendent’s Office after the above stated time even though the envelope may reflect a postmark prior to the above stated date. The Board reserves the right to accept or reject any or all bids. The decision of the Board will be final. No bid may be withdrawn by any bidder for a period of thirty (30) days after bids are opened. Timothy Smith, Chairman Calhoun County School Board ATTEST: Wilson T. McClellan, Superintendent Calhoun County Schools Legal Notice IN THE CIRCUIT COURT OF THE FOURTEENTH JUDICIAL CIRCUIT IN AND FOR CALHOUN COUNTY, FLORIDA PROBATE DIVISION CASE NO: 12-28PR IN RE: Estate of C.L. CAPPS, deceased. NOTICE OF ADMINISTRATION AND NOTICE TO CREDITORS The Administration of the estate of C.L. CAPPS, deceased, whose date of death was November 4, 2011, and whose social security number is xxx-xx-5468, is pending in the Circuit Court for CALHOUN County, Florida, Probate Division, the address of which is 20859 SE Central Avenue, Blountstown, Florida, 32424. The estate is testate. The name and address of the personal representative and the personal representative’s attorney are set forth below. Any interested person on whom a copy of the notice of administration is served who challenges the qualification of the personal representative, venue, or jurisdiction of the court is required to file any objection with the court in the manner provided in the Florida Probate Rules within the time required by law or those objections are forever barred. Any person entitled to exempt property is required to file a petition for determination of exempt property WITHIN THE TIME PROVIDED BY LAW OR THE RIGHT TO EXEMPT PROPERTY IS DEEMED WAIVED. A surviving spouse seeking an elective share must file an election to take elective share WITHIN THE TIME PROVIDED BY LAW. All creditors of the decedent and other persons having claims or demands against decedent’s estate on whom a copy of this notice is required to be served must file their claims with this court WITHIN THE LATER OF 3 MONTHS AFTER THE TIME OF THE FIRST PUBLICATION OF THIS NOTICE OR 30 DAYS AFTER THE DATE OF SERVICE OF A COPY OF THIS NOTICE ON THEM. All other creditors of the decedent and other persons having claims or demands against decedent’s estate must file their claims with this court WITHIN 3 MONTHS AFTER THE DATE OF THE FIRST PUBLICATION OF THIS NOTICE. ALL CLAIMS NOT FILED WITHIN THE TIME PERIODS SET FORTH IN SECTION 733.702 OF THE FLORIDA PROBATE CODE WILL BE FOREVER BARRED. NOTWITHSTANDING THE TIME PERIODS SET FORTH ABOVE, ANY CLAIM FILED TWO (2) YEARS OR MORE AFTER THE DECEDENT’S DATE OF DEATH IS BARRED. The date of first publication of this notice is May 23, 2012. Personal Representative: HAZEL IRENE CAPPS 20282 SE CL Capps Road BLountstown, FL 32424 Attorney for Personal Representative: WADE MERCER, ESQ. Mercer Law Office 4431 Lafayette Street Marianna, FL 32446 (850) 526-3633 Florida Bar No. 0059587 Legal Notice IN THE CIRCUIT COURT FOR CALHOUN COUNTY, FLORIDA PROBATE DIVISION File No.: 2012-PR-0014 IN RE: ESTATE OF JEANNIE M. BROOKS, Deceased. NOTICE TO CREDITORS The administration of the estate of Jeannie M. Brooks, deceased, whose date of death was January 13, 2012, is pending in the Circuit Court for Calhoun County, Florida, Probate Division, the address of which is 20859 Central Avenue E, Blountstown, Florida 32424. The names and addresses of the personal representative and the personal representative’s attorney are set forth below. All creditors of the decedent and other persons having claims or demands against decedent’s estate on whom a copy of this notice is required to be served must file their claims with this court WITHIN THE LATER OF 3 MONTHS AFTER THE TIME OF THE FIRST PUBLICATION OF THIS NOTICE OR 30 DAYS AFTER THE DATE OF SERVICE OF A COPY OF THIS NOTICE ON THEM. All other creditors of the decedent and other persons having claims or demands against decedent’s estate must file their claims with this court WITHIN 3 MONTHS AFTER THE DATE OF THE FIRST PUBLICATION OF THIS NOTICE. ALL CLAIMS NOT FILED WITHIN THE TIME PERIODS SET FORTH IN SECTION 733.702 OF THE FLORIDA PROBATE CODE WILL BE FOREVER BARRED. NOTWITHSTANDING THE TIME PERIODS SET FORTH ABOVE, ANY CLAIM FILED TWO (2) YEARS OR MORE AFTER THE DECEDENT’S DATE OF DEATH IS BARRED. The date of first publication of this notice is May 23, 2012. Personal Representative: James Brooks 12088 NW Archie Brooks Lane Altha, Florida 32421 Attorney for Personal Representative: Kathleen K. DeMaria Attorney for Personal Representative Florida Bar No. 503789 Smith, Sauer & DeMaria Post Office Box 12446 Pensacola, Florida 325912446 Telephone: (850) 4342761 Legal Notice ADMINISTRATIVE PROCEDURES ACT The Calhoun County School Board proposes to amend Policies 6.541 for the Calhoun County Schools. ADMINISTRATIVE PROCEDURES ACT CALHOUN COUNTY SCHOOLS CHAPTER 6 – HUMAN RESOURCES Amend Policies: Policy 6.541 Annual/Vacation Leave The entire proposal is available for viewing at the School Superintendent’s Office, Room G-20, Calhoun County Court House, Blountstown, Florida. A hearing will be held on the above policy in the Cooperative Extension Building at 20816 Central Avenue East in Blountstown, Florida at the Regular School Board meeting beginning at 5:00 P.M., CDT, Thursday, June 14, 2012. Timothy G. Smith, Board Chair Calhoun County School Board Attest: Wilson T. McClellan, Superintendent Calhoun County Schools Legal Notice NOTICE OF PUBLIC SALE MALLORY TOWING & RECOVERY, INC. gives Notice of Foreclosure of Lien and intent to sell these vehicles on June 4, 2012, 2:00 p.m. at 18114 SR 20 W., BLOUNTSTOWN, FL 32424-4834, pursuant to subsection 713.78 of the Florida Statutes. MALLORY TOWING & RECOVERY, INC. reserves the right to accept or reject any and/or all bids. 1997 PONTIAC 1G2JB1247V7540467 MALLORY TOWING & RECOVERY, INC.

Be First to Comment

    Leave a Reply

    Your email address will not be published.